Hutton Contracting Co. v. City of Coffeyville
487 F.3d 772 | Court of Appeals for the Tenth Circuit | 2007
Holding Summary
A contractor is responsible for supplier delays under a force-majeure clause, and liquidated damages provisions are enforceable when reasonable at contract formation, even if actual damages differ.
A contractor is responsible for the unexcused performance failures of its subcontractor.
Related Cases
Gall v. United States
Appellate courts must review all sentences under an abuse-of-discretion standard regardless of whether they fall inside or outside the Guidelines range, and cannot require extraordinary circumstances to justify sentences outside the range.
Piotrowski v. City of Houston
Municipal liability under § 1983 requires proof of official policy as the moving force; isolated employee misconduct insufficient, and equal protection claim time-barred.
Adarand Constructors, Inc. v. Pena
Federal race-based classifications must be analyzed under strict scrutiny regardless of whether they benefit or burden minorities, and the Fifth Amendment's equal protection obligation equals the Fourteenth Amendment's.
Northeastern Florida Chapter of the Associated General Contractors of America v. City of Jacksonville
An association of contractors has standing to challenge a minority set-aside ordinance without proving any member would have won a contract absent the ordinance; the injury is denial of equal competitive opportunity, not loss of a specific contract.
In Re Kellogg Brown & Root, Inc.
The Civil Commitment of Sexually Violent Predators Act is civil, not criminal, and does not violate due process even when applied to incompetent defendants.
Edwin P. Harrison, and United States of America, Party in Interest v. Westinghouse Savannah River Company
The Fourth Circuit reversed the district court's dismissal, holding that the False Claims Act broadly reaches false statements made to obtain government contract approval, not just false payment claims themselves.