Southwestern Engineering Company, Cross-Appellant v. Cajun Electric Power Cooperative, Inc., Cross-Appellee
915 F.2d 972 | Court of Appeals for the Fifth Circuit | 1990
Holding Summary
A contractor may recover unabsorbed overhead costs incurred during a suspension period under an equitable adjustment clause, but cannot recover the full contract price upon termination for convenience when the contract limits cancellation charges to actual costs incurred.
Unabsorbed overhead is properly includable in equitable adjustment if contractor proves changes idled facilities.
Related Cases
Texas Natural Resource Conservation Commission v. IT-Davy
Sovereign immunity bars a contractor's breach-of-contract suit against a state agency absent express legislative consent; neither the agency's conduct, contract terms, nor general statutes waive immunity from suit.
Martin K. Eby Construction Company, Inc. v. Dallas Area Rapid Transit
A contractor must exhaust administrative remedies established by a regional transportation authority before pursuing breach of contract claims in court, even when the authority lacks governmental immunity from suit.
Edwin P. Harrison, and United States of America, Party in Interest v. Westinghouse Savannah River Company
The Fourth Circuit reversed the district court's dismissal, holding that the False Claims Act broadly reaches false statements made to obtain government contract approval, not just false payment claims themselves.
General Services Commission v. Little-Tex Insulation Co.
The State does not waive sovereign immunity from breach-of-contract suits by accepting contract benefits; Chapter 2260's administrative procedure is the exclusive remedy for such claims.
Green International, Inc. v. Solis
No-damages-for-delay clauses in construction contracts need not meet the conspicuousness requirement established in Dresser for exculpatory negligence clauses, and such clauses are enforceable to bar delay damages absent specific exceptions.
Flameout Design & Fabrication, Inc. v. Pennzoil Caspian Corp.
Summary judgment for defendants was properly granted because Flameout failed to satisfy the statute of frauds for an alleged three-year contract, as the three documents cited did not constitute a signed, enforceable written agreement for the sale of goods.