United States of America for the Use and Benefit of T.M.S. Mechanical Contractors, Inc., Cross-Appellee v. Millers Mutual Fire Insurance Company of Texas, Third-Party Cross-Appellant v. The Craftsmen, Inc., Third-Party and Joseph Breedlove, J.D. Richmond, Jr. And Doris D. Richmond, Third-Party
942 F.2d 946 | Court of Appeals for the Third Circuit | 1991
Holding Summary
A subcontractor can recover from a Miller Act surety for actual out-of-pocket costs of labor and materials caused by delay, but cannot recover for termination costs or profits on delay expenses.
Subcontractor can recover increased out-of-pocket costs for labor and materials caused by delay.
Related Cases
General Services Commission v. Little-Tex Insulation Co.
The State does not waive sovereign immunity from breach-of-contract suits by accepting contract benefits; Chapter 2260's administrative procedure is the exclusive remedy for such claims.
Green International, Inc. v. Solis
No-damages-for-delay clauses in construction contracts need not meet the conspicuousness requirement established in Dresser for exculpatory negligence clauses, and such clauses are enforceable to bar delay damages absent specific exceptions.
Rocor International, Inc. v. National Union Fire Insurance Co. of Pittsburgh
An insured may assert an article 21.21 claim against its excess liability carrier for unfair claim settlement practices, but liability requires proof of a proper settlement demand within policy limits that an ordinarily prudent insurer would accept.
EBC, Inc. v. Clark Building System, Inc.
A supplier cannot enforce a payment obligation against a project owner based on a letter offering optional direct payment arrangements, where the supplier's own deposition testimony demonstrates it never understood the letter as a binding contract.
Sage Street Associates v. Northdale Construction Co.
Texas Constitution's usury provision applies only to lending transactions, not to judicially-awarded prejudgment interest, which derives from court order rather than commercial agreement.
El Paso Field Services, L.P. and Gulfterra South Texas, L.P. F/K/A El Paso South Texas, L.P. v. Mastec North America, Inc. and Mastec, Inc.
Contract clearly allocated all risk of undiscovered foreign pipeline crossings to contractor despite owner's due diligence obligation, as contractor assumed full responsibility for site conditions notwithstanding any owner representations.